Y1DA--PROJECT 675-23-801, Bid-Build (BB) Improve Lake Baldwin Electrical Distribution

Solicitation / RFP / RFQ

This document is a solicitation for Project 675-23-801, a Bid-Build (BB) project to improve the Lake Baldwin Electrical Distribution system. The Department of Veterans Affairs, Network Contracting Office 8 (NCO 8), is issuing this solicitation.

This solicitation details the requirements for the electrical distribution improvement project. Specific tasks, products, or services are not detailed in the provided metadata, but the project title indicates work on the electrical distribution system.

This appears to be a completed award, not an active solicitation. The award number is 36C24826C0018, with an award date of 04-14-2026 and an award amount of $3,266,684.55.

Information regarding proposal submission or evaluation criteria is not available in the provided metadata.

The original set-aside for this opportunity was Service-Disabled Veteran-Owned Small Business (SDVOSB).

This document appears to be an award notice rather than a solicitation document. The original solicitation number was 36C24826Q0104. The awarded contractor is MISSION CRITICAL ELECTRICAL & MEP SOLUTIONS, LLC.

Amendment / Modification

This document is Amendment 0001 to Solicitation 36C24826Q0104.

• Refers to Solicitation 36C24826Q0104 for details.
• Includes attached documents: Amendment 36C24826Q0104 0001, RFI Attachment No. 8, RFI Attachment No. 9, RFI Attachment No. 10, and PRE-BID Site Visit SIGN-IN SHEET for 36C24826Q0104.

Bidders should refer to this amendment and the attached documents for updated information regarding the solicitation. Specific changes to requirements, deadlines, or evaluation factors are not detailed in this summary but are expected to be within the referenced amendment and attachments.

Form / Attachment / Pricing Sheet

This document appears to be an attachment or form related to a key interlock system, likely for electrical equipment such as circuit breakers. It provides identification and technical details for a specific interlock unit.

• Interlock Unit Identification: Includes an I.D. number (5013-22548) and an S.O. number (61846).
• Manufacturer: KIRK Key Interlock, with contact information for Massillon, Ohio, USA and a website (www.kirkkey.com).
• Technical Specifications: Mentions "Interrupting Capacity - RMS Symmetrical Ampere" and "3 POLE", indicating it's for a three-pole electrical device.
• Compliance: Shows a CE marking.

This document is relevant to bidders who need to understand the specific safety and interlocking mechanisms associated with the electrical components of the opportunity. It may be required for proposal preparation, especially if the opportunity involves electrical system upgrades, maintenance, or installation where specific interlock systems are mandated.

Other / Unclassified

This document is an attendance sign-in sheet for a pre-bid site visit. It records the names, titles, company affiliations, and contact information of individuals who attended the site visit for the "BID-BUILD (BB) IMPROVE LAKE BALDWIN ELECTRICAL DISTRIBUTION" project.

This document is relevant to bidders as it indicates which companies and individuals participated in the site visit. This can provide insight into potential competitors or partners who have a vested interest in the opportunity. The sign-in sheet also confirms the date and time of the site visit, which was associated with Solicitation # 36C24826Q0104.

Form / Attachment / Pricing Sheet

This document provides product data for an ASCO 7000 Series Automatic Transfer Switch. It serves as an identification and specification label for the equipment.

• Product Name: ASCO 7000 Series Automatic Transfer Switch
• Ratings: 260 Amps, 480 Volts, 50-60 Hz, 3 Phase
• Factory Set Frequency: 60 Hz
• Product Data: Includes Catalog Number (CAT. NO.), Bill of Materials (BOM), Serial Number (SERIAL NO.), and Sales Order Number (S/O NO.).
• Associated Drawings/Manuals: References for Wiring Diagram, Outline & Mounting, Operator's Manual, and Control Panel User's Guide.
• Safety Warning: "NO USER SERVICEABLE PARTS OR SETTINGS UNDER THIS COVER. COVER SHOULD BE REMOVED BY QUALIFIED SERVICE TECHNICIAN ONLY."

This information is crucial for bidders to identify the specific model and specifications of the Automatic Transfer Switch being referenced in the opportunity. It helps in understanding the technical requirements, potential compatibility with existing systems, and the need for specialized service or installation personnel. The referenced manuals and drawings are essential for detailed planning and response preparation.

Form / Attachment / Pricing Sheet

This document appears to be an attachment to a Request for Information (RFI) and contains images of electrical breaker panels and their components. It serves as a visual reference for the existing electrical infrastructure.

• Images of electrical breaker panels, including labels for specific breakers (e.g., 'PANEL NBH', 'MCC ABC2', 'IRRIGATION PUMP', 'SPARE', 'LAB').
• Close-up views of individual circuit breakers, detailing their specifications such as amperage, voltage, pole count, and interrupting rating.
• Manufacturer information (GE Spectra RMS) and model numbers for the breakers.
• Warning labels indicating the risk of electrical shock.
• Wire size and torque specifications for connections.

This attachment provides visual and technical details about the current electrical system. Bidders responding to an RFI or subsequent solicitation should use this information to understand the existing conditions, assess the scope of potential work, and prepare more accurate proposals related to electrical systems or maintenance.

Amendment / Modification

This amendment (0001) to Solicitation 36C24826Q0104 provides responses to Requests for Information (RFIs) and includes several attachments.

• RFI Responses: The document contains detailed responses to 34 RFIs, covering various aspects of the project including:

  • Use of past performance questionnaires (PPQs) and CPARS.
  • Submission requirements for Specialized Experience Form and PPQ.
  • Clarifications on conduit bends, fire pump ATS, and breaker specifications.
  • Details on rebar for concrete-encased duct banks.
  • Confirmation of allowed work hours and shutdown windows.
  • Requirements for load-break capability on transformers.
  • Preferred manufacturer (ASCO 7000 Series) for Medium Voltage ATS replacements.
  • Specific requirements for Fire Pump ATS.
  • Clarification on "S&C Vista Switch or equal" and submission of CPARS.

• Attachments: Includes Attachments #2, #3, #9, #10, and the Site Visit Sign-in Sheet.

• The quote submission due date and time has been extended to February 9, 2026, at 1:00 PM EST.

• The period for questions and answers has closed.

• All Offerors are required to acknowledge receipt of this amendment.

Form / Attachment / Pricing Sheet

This document is an Excel spreadsheet designed to capture the base offer price breakdown from potential offerors. It serves as a template for vendors to detail their proposed costs, enabling the government to perform price analysis.

• The spreadsheet includes sections for Offeror Name, Address, and Project details.
• It requires a breakdown of costs by construction divisions (e.g., Division 1 - General Requirements, Division 2 - Existing Conditions, etc.).
• Columns are provided for Labor Cost, Material Cost, and Total Cost for each division.
• Subtotals for divisions and overall subtotals are included.
• Fields for Overhead %, Profit %, and Bond % are present, along with their respective subtotals.
• The final section is for the Total Base Offer Cost.

Offerors must use this template to provide a detailed cost breakdown of their base offer. This is crucial for avoiding lump-sum pricing and facilitating the government's price analysis. Failure to provide a comprehensive breakdown may impact proposal evaluation. All cost-related fields (Labor, Material, Total, Overhead, Profit, Bond) are currently set to 0.0 and must be populated by the offeror.

Form / Attachment / Pricing Sheet

This document is a General Decision Number (GDN) for wage determinations under the Davis-Bacon Act. It specifies the prevailing wage rates and fringe benefits that must be paid to various laborers and mechanics employed on construction projects in Orange County, Florida. This document is crucial for contractors to understand labor costs and ensure compliance with federal regulations.

• General Decision Number: FL20260218
• State: Florida
• County: Orange County
• Construction Type: Building Construction Projects (excluding single-family homes and apartments up to 4 stories).
• Classifications and Rates: Lists specific job classifications (e.g., Asbestos Worker, Carpenter, Electrician, Operator, Plumber) with their corresponding hourly wage rates and fringe benefit rates.
• Footnotes: Provides additional details on employer contributions for vacation pay and lists paid holidays.
• Executive Orders: References Executive Order 13706 (Paid Sick Leave) and Executive Order 13658 (Minimum Wage for Federal Contractors), outlining contractor obligations.
• Appeals Process: Details the procedure for appealing wage determinations.

Bidders must use this wage determination to accurately calculate labor costs for their proposals. Failure to comply with these prevailing wage rates can lead to contract violations and penalties. The listed rates and fringe benefits are the minimum required for covered employees on this project.

Form / Attachment / Pricing Sheet

This document contains electrical symbols, abbreviations, and general notes for the Lake Baldwin Site Electrical Upgrades project. It serves as a reference for understanding the various symbols used in the electrical drawings and the project's specific requirements and standards.

• Symbols: A comprehensive list of symbols used for electrical devices, lighting fixtures, power distribution, telecommunications, lightning protection, and grounding.
• Abbreviations: A detailed glossary of electrical and construction-related abbreviations used throughout the project documents.
• General Notes: Important instructions and requirements for the contractor, including:
  • Device mounting heights.
  • Wire sizing for voltage drop.
  • Conduit fill and routing.
  • Sealing of penetrations.
  • Verification of equipment and dimensions.
  • Compliance with codes and standards (NEC, IBC, ADA, etc.).
  • GFCI protection requirements.
• Codes and Standards: Lists applicable national, international, local, and owner-specific codes and standards.
• Testing and Special Inspections: Outlines requirements for third-party testing for specific electrical equipment and systems.

This document is crucial for bidders to accurately interpret the electrical plans and specifications. Understanding the symbols and abbreviations is essential for correctly estimating materials, labor, and compliance requirements. The general notes and codes/standards sections provide critical information on installation methods, material specifications, and regulatory compliance, directly impacting the scope and execution of the electrical work.

Form / Attachment / Pricing Sheet

This document, "100% Specification," outlines the detailed specifications for the "Improve Lake Baldwin Electrical Distribution" project (Project Number 675-23-801) at the Lake Baldwin – Orlando VA Medical Center. It serves as a comprehensive guide for bidders on the technical requirements and standards for the electrical distribution improvements.

The document is structured into divisions and sections, detailing requirements for various aspects of the project, including:

• General Requirements (Division 01)
• Existing Conditions (Division 02)
• Concrete (Division 03)
• Thermal and Moisture Protection (Division 07)
• Finishes (Division 09)
• Specialties (Division 10)
• Electrical (Division 26)
• Earthwork (Division 31)
• Exterior Improvements (Division 32)

Each section lists specific standards, materials, and procedures that must be followed. For example, Division 26 (Electrical) includes requirements for electrical installations, medium-voltage cables, grounding and bonding, raceways, transformers, switchgear, panelboards, wiring devices, and surge protective devices.

This document is critical for potential bidders as it provides the detailed technical specifications that will form the basis of the contract. Bidders must thoroughly review these specifications to understand the scope of work, material requirements, installation procedures, and quality control standards to accurately estimate costs, develop proposals, and ensure compliance if awarded the contract. The document is essential for understanding the technical intricacies of the electrical distribution improvements required for the project.

Form / Attachment / Pricing Sheet

This document is the VAAR 852.219-75 VA Notice of Limitations on Subcontracting—Certificate of Compliance for Services and Construction (JAN 2023) (DEVIATION). It requires offerors to certify their compliance with subcontracting limitations if awarded a contract.

• Services Contracts: Offerors must certify that they will not pay more than 50% of the contract amount to firms not certified as SDVOSBs or VOSBs. Work subcontracted by similarly situated certified SDVOSB/VOSB subcontractors counts towards this limit.
• General Construction Contracts: Offerors must certify that they will not pay more than 85% of the contract amount to firms not certified as SDVOSBs or VOSBs. Work subcontracted by similarly situated certified SDVOSB/VOSB subcontractors counts towards this limit. Costs of materials are excluded.
• Special Trade Construction Contracts: Offerors must certify that they will not pay more than 75% of the contract amount to firms not certified as SDVOSBs or VOSBs. Work subcontracted by similarly situated certified SDVOSB/VOSB subcontractors counts towards this limit. Costs of materials are excluded.
• Certification Statement: A formal certification must be completed, signed, and returned with the offeror's bid, quotation, or proposal.
• Consequences of Non-Compliance: False certifications are subject to penalties under Title 18, United States Code, Section 1001. Failure to comply with subcontracting limitations may result in referral to the VA Suspension and Debarment Committee, fines, or prosecution. The VA may require documentation to verify compliance.

This is a mandatory certification for all offerors. Failure to complete and submit this form with the bid, quotation, or proposal will result in the offer being deemed ineligible for award. Bidders must understand and agree to the specific subcontracting limitations applicable to the contract type (Services, General Construction, or Special Trade Construction) to ensure compliance.

Form / Attachment / Pricing Sheet

This document is a Past Performance Questionnaire required for offerors submitting a bid to the Department of Veterans Affairs (VA). Its purpose is to gather feedback from previous clients regarding the contractor's performance on past projects. This feedback will help the VA assess the offeror's technical capability, quality of services, and timeliness.

• Contractor Information: To be completed by the bidding contractor, including company name, address, contact details, and project information (title, period of performance, contract number, description of work, contractor's role).
• Client/Respondent Information: To be completed by the reference contact, including company name, address, and contact details.
• Performance Information: A rating scale (1-5) for various performance areas such as Management, Quality Control, Regulations, Problem Resolution, Schedule, and Warranty Response. Narrative explanations are required for ratings of 2 or 3.
• Recommendations: A section for the client to indicate if they would award another contract to the contractor and to provide comments.
• Remarks: An open section for additional comments, including the two best performance traits displayed by the contractor.

Bidders must complete the "Contractor Information" section and forward this questionnaire to their previous clients. The completed questionnaires, submitted by the clients to the Contracting Officer by the offer due date (February 9, 2026), will be used by the VA as part of the evaluation factors for Experience, Past Performance, and Technical Qualifications. This document directly impacts the proposal evaluation and therefore requires careful attention from bidders to ensure their past performance is accurately and favorably represented.

Form / Attachment / Pricing Sheet

This document is the "EMR FORM - FORM FOR BIDDER/OFFEROR TO COMPLETE & SUBMIT WITH PROPOSAL - Pre-Award Contractor Evaluation Form." It is designed to collect information from potential bidders regarding their safety and health performance.

• Company Information: Name, Address, Telephone, Fax, Email, Contact Person.
• OSHA 300 Data: Bidders must provide data for the past three years (2022-2025) including:
  • Number of man-hours (jobsite and office).
  • Number of cases involving days away from work, restricted activity, or both.
  • Days away, restricted, or transferred rate (DART Rate).
  • Number of serious, willful, or repeat violations from OSHA within the last 3 years (with explanations for any violations).
• Required Attachments: Copies of OSHA 300 and 300a Forms.
• NAICS Code: Six-digit North American Industrial Classification System (NAICS) Code for the acquisition.
• Safety and Health Program Administrator: Name or title of the person administering the company's Safety and Health Program.
• Insurance Experience Modification Rate (EMR): EMR for the past 3 years. An EMR greater than 1.0 disqualifies the contractor.

This form is critical for bidders to complete accurately as it directly assesses their safety record and compliance. Specific criteria, such as an EMR greater than 1.0 or certain OSHA violations, can lead to disqualification. The information provided will be used in the pre-award evaluation process.

Form / Attachment / Pricing Sheet

This document is a Specialized Experience Form designed to collect information from offerors regarding their past performance on relevant contracts. It is used to evaluate the offeror's specialized experience and its relevancy to the current procurement.

• Contractor Information: Details of the awarded contract, including firm name, address, DUNS and Cage codes, contact information, contract/task order number, and award date.
• Project Details: Project title, name, location, and the offeror's role (Prime Contractor, Subcontractor, etc.) and the percentage of work performed.
• Scope of Work and Responsibilities: A detailed description of the project's scope and the offeror's specific roles, explaining how the work performed is relevant to the current solicitation.
• Challenges and Resolutions: Information on any difficulties, obstacles, or unforeseen conditions encountered during performance and how they were resolved.
• Performance Period and Completion: Contract start and completion dates (original and actual), and reasons for any non-completion.
• Project Completion Status: Whether the project is 50% or more complete.
• Contract Termination: Details on any terminated contracts and the reasons.
• Contract Pricing: Original and final contract prices, with explanations for any differences.

Bidders must complete this form accurately and thoroughly to demonstrate their qualifications and experience. The information provided will be used to evaluate the offeror's suitability for the opportunity. Failure to provide sufficient detail or meet the minimum project requirements (e.g., three projects) may result in a lower rating or disqualification.

Form / Attachment / Pricing Sheet

This document contains structural calculations for a caisson (pole footing) embedded in soil, specifically for the Lake Baldwin Emergency System Study project in Orlando, Florida. It details the analysis performed by Simply Structural Inc. for AESUS Design Group.

• Project Information: Includes client, project description, address, and engineer details.
• General Information: Specifies building code (2020 Florida Building Code), assumed allowable bearing pressure (1500 psf), and footing shape (circular, 18.0 in diameter).
• Load Combinations: Analyzes various load combinations including Dead Load (D), Wind (W), and Roof Live Load (Lr), with specific values for lateral concentrated loads, distributed loads, and moments.
• Calculations: Presents results for different load combinations, showing required depth, actual pressure at depth, allowable pressure, and soil increase factors.
• Wind Loads: Includes calculations for wind pressures on open buildings, roof pressures (normal and parallel to ridge), and pressures on fascia panels and components/cladding.

This document provides critical structural engineering calculations related to the foundation design for a canopy column. Bidders can use this information to understand the structural integrity requirements and the basis for the foundation design, which may be relevant for understanding the overall project scope and potential site conditions.

Form / Attachment / Pricing Sheet

This document is a 100% Emergency Analysis Report for the Improve Lake Baldwin Electrical Distribution project (675-23-801) at the Lake Baldwin – Orlando VA Medical Center. Its purpose is to explore potential solutions and their feasibility for providing generator-backed power to the entire campus. It outlines existing conditions, presents four potential solutions, and details the selected solution.

• Executive Summary: Outlines the report's purpose, existing conditions, and the selected solution.
• Existing Conditions: Details the current 12,470-volt medium voltage (MV) electrical distribution system, including incoming utility feeds, MV switches, automatic transfer switches (ATSs), and transformers serving various buildings.
• Normal Electrical Demand: States the campus peak demand recorded at 1,728 KW in July 2022.
• Emergency Distribution: Describes the existing emergency distribution system, powered by three 750 kW generators feeding a 3,000 A paralleling switchboard. It lists loads directly fed by the paralleling board and ATSs, noting which buildings are partially or fully backed up by emergency power.
• Proposed Solution: Details a selected solution focused on cost-effectiveness, constructability, and minimal intrusiveness. It involves replacing the existing generator paralleling switchboard, adding a new MV 6-way switchgear, and a new step-up transformer to inject emergency power at the MV level. It also includes demolition of existing equipment (MV-MWS-NO.1 and 502-SWBD-EM) and installation of new equipment.
• Pros: Minimal demolition, minimal new equipment, maintenance of existing MV infrastructure, and minimum underground work.
• Cons: Requires integration of new MV switchgear with existing ATSs, and does not address State-owned buildings currently fed from the VA MV distribution system.
• Phasing Considerations: Discusses how construction can be phased to minimize normal power outages and maintain emergency power capabilities.

This report provides critical technical details about the existing electrical infrastructure and the proposed solution for enhancing emergency power. Bidders can use this information to understand the scope of work, the existing system's complexities, the specific equipment involved, and potential challenges or considerations for the project. It helps in assessing the technical requirements and feasibility of the opportunity.

Form / Attachment / Pricing Sheet

This document is a "100% Design Narrative" for the "Improve Lake Baldwin Electrical Distribution" project. It provides detailed narratives for the electrical, civil, and structural aspects of the project, along with a design schedule. It serves to explain the design decisions, scope of work, and technical requirements for the project.

• Electrical Narrative: Details specific electrical deficiencies at the Lake Baldwin and Lakemont VA campuses and outlines the proposed solutions, including replacement of tie breakers, transformers, and ATS units, as well as relocating overhead power lines underground. It also includes general design guidelines and project scope.
• Civil Narrative: References design standards and existing conditions, and outlines site demolition and improvements, including electrical gear, concrete encased duct banks, and concrete pads.
• Structural Narrative: Describes the scope of work related to extending existing canopies and concrete pads, including specifications for concrete work and compliance with VA design criteria and building codes.
• Design Schedule: Outlines the project timeline.

This document provides critical technical details about the project's scope, requirements, and design. Bidders should review the Electrical, Civil, and Structural Narratives to understand the specific work to be performed, the existing conditions, and the proposed solutions. This information is essential for accurately estimating costs, developing a technical proposal, and understanding any site-specific requirements or constraints.

Forms / Attachments / Pricing Sheets

This document contains the "100 Drawings" for the "IMPROVE LAKE BALDWIN ELECTRICAL DISTRIBUTION" project at the Department of Veterans Affairs, Lake Baldwin - Orlando VA Medical Center. These drawings provide detailed plans, site layouts, electrical schematics, and technical specifications necessary for understanding and executing the electrical upgrade project.

• Cover Sheet (GI.001): Project overview, consultant information, and list of issued sheets.
• Site Plans (AS100, ED-101, ED-102, EP-101, EP-103): Depict the overall layout of the Lake Baldwin and Lakemont campuses, showing existing and proposed electrical infrastructure, demolition areas, and site work.
• Enlarged Plans (AE103): Provide detailed views of specific areas, including equipment pads and canopy extensions.
• Foundation Plans (S101): Detail the structural requirements for foundations.
• Civil Plans (C002, C003, C101, C102, C300): Outline site utilities, grading, and general civil engineering notes.
• Electrical Details (EP-401, EP-402, EP-403): Show specific construction details for ductbanks, firestopping, grounding, and labeling.
• One-Line Diagrams (EP-601, EP-602, EP-603): Illustrate the electrical power distribution system, including transformers, switchgear, and load connections for both demolition and new construction phases.
• Symbols and Abbreviations (E-001): A comprehensive list of symbols and abbreviations used throughout the electrical drawings.

These drawings are critical for bidders to understand the scope of work, existing conditions, proposed electrical system modifications, demolition requirements, and specific installation details. They form the basis for estimating costs, planning execution, and ensuring compliance with all technical specifications and safety standards for the "Improve Lake Baldwin Electrical Distribution" project.

Solicitation / RFP / RFQ

This solicitation is for construction services to "Improve Lake Baldwin Electrical Distribution" at the Orlando VA Healthcare System (OVAHCS) Lake Baldwin Campus and Lakemont Campus. The project aims to upgrade specific electrical deficiencies by repairing, relocating, and replacing electrical equipment.

• Replace the tiebreaker in Building 500's Switchboards 2 and 3.

• Add a disconnecting means at the Orlando Utilities Commission (OUC) south utility feeder.

• Replace the transformer in front of Building 3130 and relocate overhead power lines underground.

• Replace the transformer between Buildings 504 and 502 and provide emergency generator-backed power to Building 504.

• Replace the fire pump ATS.

• Replace medium voltage ATSs No. 2, 3, and 4.

• Relocate or Replace ATS in the chiller yard at the Lakemont campus.

• All work must comply with the 100% design drawings and specifications.

• Adherence to National Electrical Code (NEC) and other applicable standards.

• Contract Type: Firm-Fixed-Price.

• Magnitude of Construction: Between $1,000,000 and $4,000,000.

• Period of Performance: 270 calendar days from the Notice to Proceed.

• Site Visit: January 15, 2026, at 1:00 PM EST.

• Request for Information (RFI) due: January 20, 2026, at 1:00 PM EST.

• Quotes due: February 9, 2026, at 1:00 PM EST.

• Offers must be submitted electronically via email.

• Evaluation will be based on a comparative evaluation of quotes, considering non-price factors (significantly more important than cost or price) and price.

• This requirement is set aside for U.S. Small Business Administration certified, Service-Disabled Veteran-Owned Small Businesses (SDVOSB).

• Offerors must be registered in SAM.gov and certified in SBA's VetCert program.

• Funds are not currently available, and award will be made only after appropriated funds are made available.

• Offerors must be actively registered in SAM.gov and SBA.gov.

• A bid guarantee of 20% of the bid price or $3,000,000, whichever is less, is required.

• Performance and payment bonds are required within 10 calendar days of award.

Solicitation / RFP / RFQ

This solicitation seeks construction services for Project 675-23-801, "Bid-Build (BB) Improve Lake Baldwin Electrical Distribution" at the Department of Veterans Affairs Orlando Veterans Affairs Healthcare System (OVAHCS) Lake Baldwin and Lakemont campuses in Orlando, FL. The project involves furnishing all labor, materials, tools, equipment, and supervision necessary for the construction, in accordance with provided 100% design drawings and specifications.

• Construction services for the "Improve Lake Baldwin Electrical Distribution" project.

• Work must be in accordance with 100% design drawings and specifications.

• Contractor shall furnish all necessary construction elements.

• Period of Performance: 270 calendar days from the issuance of the Notice to Proceed (NTP).

• Estimated Value: Between $1,000,000.00 and $4,000,000.00.

• Response Date/Time: February 9, 2026, 1:00 PM Eastern Time, New York, USA.

• Contracting Office: Department of Veterans Affairs, Network Contracting Office 8 (NCO 8), Orlando VA Healthcare System, 13800 Veterans Way, Orlando FL 32827.

• Point of Contact: Elizabeth Romero, Contracting Officer, elizabeth.romero@va.gov, (407) 399-7526.

• This solicitation is 100% set-aside for Service-Disabled Veterans-Owned Small Businesses (SDVOSBs).

• NAICS Code: 221122

• Product Service Code: Y1DA

• Numerous attachments are provided, including specifications, drawings, design narrative, various reports, calculations, wage determination, and forms for specialized experience, past performance, and offer breakdown. Bidders should refer to these attachments for comprehensive details.